This site uses cookies to improve your experience. To help us insure we adhere to various privacy regulations, please select your country/region of residence. If you do not select a country, we will assume you are from the United States. Select your Cookie Settings or view our Privacy Policy and Terms of Use.
Cookie Settings
Cookies and similar technologies are used on this website for proper function of the website, for tracking performance analytics and for marketing purposes. We and some of our third-party providers may use cookie data for various purposes. Please review the cookie settings below and choose your preference.
Used for the proper function of the website
Used for monitoring website traffic and interactions
Cookie Settings
Cookies and similar technologies are used on this website for proper function of the website, for tracking performance analytics and for marketing purposes. We and some of our third-party providers may use cookie data for various purposes. Please review the cookie settings below and choose your preference.
Strictly Necessary: Used for the proper function of the website
Performance/Analytics: Used for monitoring website traffic and interactions
The County entered into an agreement with the Contractor to expand a three-mile stretch of road. The contract allowed for “delay damages” if the Contractor’s request for those damages “is determined to be compensable.”. The Contract. Under the contract, the County was responsible for moving gas, water, and fiber-optic utilities.
When you are dealing with changes on a project, they can be classified, treated, reviewed, and compensated on a different basis. This Agreement becomes a part of the Contract when properly executed and approved. Take, for example, the world of changes in the construction context.
Disputes over insurance agreements can be, for example, one of those reasons. One of the project parties may feel that it’s entitled to some compensation while the insurance company, or whoever is responsible for that may have a different opinion. The reasons for a contract dispute may vary each time. Unforeseen Reasons.
I deal with these rules daily but this client’s issue helped to refresh me. The application needs to include the following information in addition to proof of workers compensation insurance: (B)(1) The applicant’s name, home address, business address, and social security number. (2) Home Improvement Contractors ( La R.S.
But it was the workforce availability at Georgia Tech and surrounding universities that really closed the deal. Nathan Deal recently announced that the company will add 800 jobs in metro Atlanta. The expansion deal came on the heels of Gov. Georgia’s economic development team provided a $1.2
Making the transition from chaos to uniformity tends to bring a bit of chaos itself because people don’t deal all that well with change, even change for the better. Well, when my wife Tammy and I were married we made an agreement. Why is that? So how do you mitigate swirling uncertainty in the minds of your staff? .
Understand the Deal. related to becoming a Principal such as the Shareholder Agreement, Deferred CompensationAgreement, Buy-Sell agreement, Company By-Laws, Articles of Incorporation, Board Minutes, Budgets, business plans, strategic plans, and Annual Reports from the past several years. Test Your Understanding.
Today, one of my legal alerts pointed me to one such case dealing with delay damages and disruption damages. The County entered into an agreement with the Contractor to expand a three-mile stretch of road. Rarely do you find a case that succinctly addresses a construction law issue. This is a must read! In County of Galveston v.
This is a painful expense, but, as he explained, it fit within the framework of the original agreement which he negotiated within his discretion (and from what I could have seen at the time, would have been a contract I would have approved.). The problems occurred from design work time and effort cost overruns.
First, you could put together a teaming agreement, signed by both parties, that outlines either the scope of work or percentage you will get. They may also be reluctant to give you a great deal of information about their strategy and advantages if they believe you may team with another prime. Does The Compensation Work For Us?
This eliminates incentives to cut corners or rush a project through, as the time spent on “getting it right” will be compensated. In a tight construction market with limited availability of builders, fixed price contracts tend to be padded to deal with uncertainties, contingencies, mistakes, etc.
Genuine independent contractors — not phony “contractors” created by scammy employees to cicumvent tax or workers compensation laws — often do the best work. We almost got caught by this one, and averted another crisis with a Tim Hortons parking lot deal and a one-line email. The “human rights” game.
The Court confirmed—what was thought to be self-evident but was thrown into doubts by the Eleventh Circuit—the principle that international arbitration agreements can be enforced by non-signatories. Converteam SAS has held that under the New York Convention, only a party to a signed arbitration agreement can compel arbitration.
Last year, the state signed an agreement with Mercedes-Benz that recognizes Shelton State Community College as one of the best in its field in preparing individuals for careers in manufacturing. Mercedes-Benz U.S. The Subaru expansion will create 500 new jobs and yield an estimated direct economic impact of more than $1.8 Herbert told us.
A business that applies for the exemption must enter into an agreement with the Governor of Alabama. The business must sign a job-creation agreement under the Advantage Arkansas program within 24 months of signing the Tax Back agreement. Must expand its labor force, make new capital investment, or prevent loss of employment.
25 MILLION DEAL-CLOSING FUND: Arizona has taken a progressive position by offering attraction funds to companies meeting performance measures that benefit both the company and the citizens of Arizona. The business must sign a job-creation agreement under the Advantage Arkansas program within 24 months of signing the Tax Back agreement.
Here, the owner and contractors would come up with an agreement and produce a formal document outlining the terms of the project. . Construction contracts come in different forms, including: Cost-Plus Contract, where contractors are compensated for all construction-related expenses.
Money is only one form of compensation. The best way to deal with this Right is for authors to stipulate what their BIM model has been created for (i.e. The usual way to deal with provision to inappropriate parties is to stipulate the work can only be provided to those directly involved in the particular project it was created for.
We organize all of the trending information in your field so you don't have to. Join 116,000+ users and stay up to date on the latest articles your peers are reading.
You know about us, now we want to get to know you!
Let's personalize your content
Let's get even more personalized
We recognize your account from another site in our network, please click 'Send Email' below to continue with verifying your account and setting a password.
Let's personalize your content