No-Damage-For-Delay Provisions and Lien Waivers Remain Enforceable — and Valuable — in New York
Constructlaw
OCTOBER 20, 2022
Pizzarotti LLC, a construction manager, sued its subcontractor, X-Treme Concrete, Inc., The court rejected X-Treme’s argument that the no-damage-for-delay provision did not bar its claim because the cause of the delay (incomplete drawings) was not within the parties’ contemplation when they executed their subcontract.
Let's personalize your content